1. Introduction
By accessing or using the website, services, or products provided by Vidisha Real Estate Developers Pvt Ltd (“Company”), you agree to comply with and be bound by these Terms and Conditions. If you do not agree to these terms, please refrain from using our services.
2. Eligibility
Our services are available to individuals over the age of 18. By using our services, you confirm that you meet this requirement and possess the legal authority to enter into a binding agreement.
3. Property Information
All information regarding properties, including prices, specifications, and availability, is subject to change without prior notice. While we strive for accuracy, errors and omissions may occur. We recommend verifying all details before making any commitments.
4. Booking and Payment
4.1 Booking: A booking is confirmed upon receipt of a signed agreement and the required booking amount.
4.2 Payment Terms: Payments should be made as per the schedule outlined in the buyer agreement. Failure to make timely payments may result in penalties or cancellation of the booking.
4.3 Cancellations: Any cancellation requests must be submitted in writing. Cancellation policies are governed by the agreement signed at the time of booking.
5. Possession and Delays
5.1 Possession: The Company will hand over possession of the property upon completion of construction and receipt of necessary approvals from local authorities.
5.2 Delays: While we strive to meet project deadlines, delays due to force majeure events (e.g., natural disasters, strikes, government actions) or unforeseen circumstances may occur. In such cases, we will notify clients and take necessary actions to minimize delays.
6. Use of Website
6.1 Content: All content on the website, including text, images, and media, is the property of Vidisha Real Estate Developers or its licensors. You may not copy, distribute, or use the content for commercial purposes without prior permission.
6.2 Third-Party Links: Our website may contain links to third-party websites for your convenience. We are not responsible for the content or practices of these websites.
7. Warranties and Representations
7.1 Property Quality: All properties are built to meet the agreed-upon specifications. However, minor variations due to construction processes may occur.
7.2 Discrepancies: In case of any discrepancies between promotional materials and actual properties, the final specifications in the agreement shall prevail.
8. Dispute Resolution
Any disputes arising from these terms or related to property transactions will be resolved through amicable negotiations. If a resolution cannot be reached, the matter will be subject to arbitration in Mumbai, India, in accordance with the Arbitration and Conciliation Act, 1996.
9. Liability Limitation
Vidisha Real Estate Developers is not liable for any indirect, incidental, or consequential damages arising from the use or inability to use our services or any issues related to project delays.
10. Amendments to Terms
We reserve the right to modify these Terms and Conditions at any time. Any updates will be posted on our website, and continued use of our services indicates acceptance of the revised terms.
11. Governing Law
These terms shall be governed and construed in accordance with the laws of India. Any legal action shall be subject to the exclusive jurisdiction of the courts in Mumbai.
12. Privacy Policy
Vidisha Real Estate Developers is committed to protecting your privacy. Any personal information collected will be handled in accordance with our Privacy Policy, which is available on our website.
13. Contact Information
For any questions or concerns regarding these Terms and Conditions, please contact us at:
Vidisha Real Estate Developers Pvt Ltd